Terms of Service

By accessing this website or engaging Ambinix Ventures Pvt Ltd for services, products or training, you agree to these terms. If you do not agree, please discontinue use of the website and our services.

We provide custom web, application and software development, business management software, technology consulting, and training and internship programs for colleges and companies.

The exact scope, timeline, deliverables and commercial terms of any engagement are governed by a separate written proposal, quotation or agreement signed with the client.

You agree to use this website lawfully and not to attempt unauthorised access, disrupt its operation, scrape its content in bulk, or misuse any form or contact channel provided on it.

All content on this website — including text, layout, graphics, logos, brand marks and code — is owned by Ambinix Ventures Pvt Ltd or its ventures and is protected by applicable law.

Content may not be copied, reproduced, republished or distributed without prior written permission. Ownership of project deliverables is defined in the relevant client agreement.

Fees, milestones, taxes and payment schedules are set out in the applicable proposal or invoice. Unless stated otherwise, invoices are payable within the period stated on the invoice.

Delayed payment may result in suspension of work, hosting or support until dues are cleared.

Program schedules, curriculum, batch sizes and certification criteria are shared before enrolment and may be customised for an institution or company.

Certificates are issued on satisfactory completion of the program requirements. Sponsorships, prizes and incubation support are discretionary and subject to the terms announced for each event.

Each party will protect the other's confidential information shared during an engagement and use it solely for the purpose of that engagement.

To the extent permitted by law, Ambinix Ventures Pvt Ltd is not liable for indirect, incidental or consequential losses arising from use of this website or our services.

Website content is provided for general information and may change without notice.

Projects may rely on third-party platforms, APIs or hosting providers. Their availability, pricing and terms are outside our control and are governed by those providers.

These terms are governed by the laws of India, and disputes are subject to the exclusive jurisdiction of the courts at Bengaluru, Karnataka.

We may revise these terms from time to time. Continued use of the website after an update constitutes acceptance of the revised terms.